Search results

Perspective - Blog

North Midland Building Limited v Cyden Homes Limited [2017] EWHC 2414 (TCC): Choose your extension of time provisions carefully

Published on 11 Oct 2017.

North Midland Building Limited v Cyden Homes confirms the primacy of the parties' contract in determining an extension of time. Specifically, in North Midland the High Court held that an amendment made to the construction contract meant that, in a situation of concurrent delay, North Midland Building Ltd (the Contractor) was not entitled to an extension of time from Cyden Homes Ltd (the Employer) and that the prevention principle, had it arisen, would not take precedence over the expressly agreed terms of the contract.

Perspective - Blog

Contractors and Insurers beware - Contractor found to bear the risk of an incorrect standard as fitness for purpose prevails in the Supreme Court

Published on 03 Aug 2017.

This morning the Supreme Court handed down its much anticipated judgment in MT Højgaard A/S v E.ON Climate & Renewables UK Robin Rigg East Limited and another [2017] UKSC 59. The Judgment should be of concern to both contractors and their insurers.

Perspective - Blog

Is it game over for ground rent?

Published on 01 Aug 2017.

Considering the recent Government proposals to change the rules on ground rent and how those proposals may affect developers.

Perspective - Blog

Complex contracts and intricate inconsistencies – a reminder of the court's approach to contractual interpretation

Published on 18 Jul 2017.

In a year in which the Supreme Court will have produced two Judgments on the topic of contractual interpretation, the TCC's judgment in 125 OBS v Lend Lease is a useful reminder of the courts' approach to resolving these disputes and their attempt to find a balance between the so-called literal and commercial approaches to interpretation.

Perspective - Blog

Even More Challenging Times – 5 More Risks Following The Grant of Planning Permission

Published on 14 Jun 2017.

This post is the second in a two-part series in which we highlight ten areas where the risk of a third party challenge against the grant of planning permission might arise. The list we have given is not exhaustive, but all issues fall within the broad parameters for judicial review grounds, being decisions which have been taken irrationality, ultra vires (outside the scope of the authority's powers), or with procedural irregularity.

Perspective - Blog

EIA – a new role for the planning system in considering the health impacts of development?

Published on 10 May 2017.

A summary of the EIA Regulations 2017 and the consideration as part of the planning application process of a proposed development's likely impacts on human health.

Perspective - Blog

Let there be light

Published on 19 Apr 2017.

The importance of light in WELL Building Standards and how it sits within the context of planning law and rights of light

Perspective - Blog

MIPIM: 10 things we learnt about you

Published on 31 Mar 2017.

A round up of things we learnt during our first experience of MIPIM week, from what to wear to how to plan your diary and make the most of your new connections

Perspective - Blog

Engaging with Development – do we always know what we need?

Published on 29 Mar 2017.

Comment on the need for public engagement in the planning and development process, following a ULI presentation on The Well-Tempered City (author Jonathan Rose)

Perspective - Blog

Finally, a victory in the on-going battle against business rates

Published on 03 Mar 2017.

The Supreme Court ruling in Newbigin v Monks represents a welcome and important victory for UK property developers.

Perspective - Blog

Green belt development - don't forget the law!

Published on 13 Feb 2017.

A review of the housing white paper in relation to green belt development noting that the Green Belt (London and Home Counties) Act 1938 is a further hurdle.

Perspective - Blog

Electronic Signatures – the future of executing documents?

Published on 03 Feb 2017.

You could be forgiven for failing to spot the release of The EU Regulation on Electronic Identification and Trust Services in the Internal Market (910/2014/EU) (the Regulation), released post EU referendum. We consider the impact of this and the Law Society's Guidance Note on electronic signatures (the Guidance Note).

Perspective - Blog

Garden Villages - are they necessary?

Published on 09 Jan 2017.

A recent Government announcement has proposed 14 sites across England to be the first garden villages, with 3 further sites to be new garden towns. But with a country full of deserted and derelict buildings, are garden villages and towns the only way forward?

Perspective - Blog

Office to Residential Permitted Development Rights – an update

Published on 08 Aug 2016.

The rights to convert a building from office use to residential without needing to submit a planning application are not new, although a recent decision from the Planning Court have brought them back to the headlines and suggest that they may be more flexible than anticipated.

Perspective - Blog

Freedom of information: access denied by ministerial veto

Published on 04 Feb 2014.

Not since September 2012 when the Attorney General exercised powers under section 53(2) of the Freedom of Information Act 2000 (FOIA) blocking the release of correspondence between Prince Charles and seven government departments has there been a matter likely to attract attention to the use of the ministerial veto.

Perspective - Blog

Court of Appeal's opinion on good faith clauses

Published on 11 Apr 2013.

In our February blog we reported on Compass Group UK and Ireland Ltd (trading as Medirest) v Mid Essex Hospital Services NHS Trust [2012] EWHC 781 (QB) and the implications of the decision on the duty to act in good faith.

Perspective - Blog

Costs overruns in Target Costs contracts

Published on 22 Mar 2013.

Who is liable for costs overruns in a Target Cost contract, and to what extent? AMEC Group recently went to the TCC to appeal against an arbitration decision which found the Secretary of State for Defence ("the Authority") would only be liable for actual costs which were reasonably and properly incurred.

Perspective - Blog

NPPF – 1 year on: smooth transition or wasted opportunity?

Published on 21 Mar 2013.

Given that over 50% of Britain's local councils are still to adopt Local Plans, is the window of opportunity for local residents to take control of development in their local area about to close?

Perspective - Blog

New Kids on the Block : alternative funders in the real estate lending market

Published on 15 Mar 2013.

Over the last couple of years, there has been a surge in real estate lending by non-bank lenders as traditional banks started withdrawing from the market.

Perspective - Blog

Good Faith Clauses

Published on 26 Feb 2013.

There is no general doctrine of good faith in English law and it is not therefore implied into contracts.

Perspective - Blog

JCT Insurance Options: what's the right fit for fit-out?

Published on 18 Feb 2013.

Where a tenant is fitting out premises within a multi-occupied building, the JCT's standard insurance options are not always appropriate and, left unaddressed, place unintended and severe risks on the tenant.

Perspective - Blog

Government property, Kirstie and Phil style?

Published on 01 Feb 2013.

Ok, so Ms Allsopp and Mr Spencer haven’t quite been called in yet, but almost.

Perspective - Blog

Is the Green Deal a great deal?

Published on 29 Jan 2013.

There is no denying the Green Deal has many advantages but consider the deal in relation to short term leases and it may not be as great as it initially seems.

Perspective - Blog

NEC3 Engineering and Construction Contract "Guidance Notes": more important than you realise for interpreting the ECC

Published on 18 Jan 2013.

Certain terms of the NEC3 Engineering and Construction Contract ('ECC') are open to interpretation, and the recent case of E-Nik Ltd v Department for Communities & Local Government [2012] EWHC 3027 (Comm) has cast into doubt whether even something as routine as VAT is crystal-clear under the ECC.

Perspective - Blog

Development incentives – but at what cost?

Published on 14 Jan 2013.

In light of what is starting to appear to be a wholehearted failure to persuade local communities to meet requisite housing targets, Nick Boles last week proposed self-proclaimed "bungs" to local communities.

Perspective - Blog

Leaving customers without signal: the task of re-building the Telecoms Code

Published on 05 Dec 2012.

Now almost 30 years old, the Electronic Communications Code (the 'Code'), falls far short of representing the needs of a swiftly developing communications network.

Perspective - Blog

H&M: Brave New World?

Published on 27 Nov 2012.

We have all been involved in lease negotiations where there are differences of opinion as to what is or is not institutionally acceptable.

Perspective - Blog

End of the line for Village Greens?

Published on 14 Nov 2012.

Nothing can be more frustrating for a developer to see its scheme delayed or worse still derailed by an application for the registration of land as a town or village green ("TVG").

Profile

Saskia Mautner

Associate

Perspective - Blog

Look to the future: Trainees take on 2019

Published on 25 Jan 2019.

The trainees didn't fare too badly with their 2018 predictions. They doubted England's ability to make it past the group stages of the World Cup, but foresaw how Brexit would dominate the news agenda. They over-optimistically predicted the introduction of automated bundling, but came very close on the value of Bitcoin. Read on to see this year's predictions.

Perspective - Blog

Brexit - a legal analysis: IP rights

Published on 28 Jun 2016.

IP rights in the UK are all influenced and moulded to a greater or lesser degree by European law.

Perspective - Publication

“Gagging orders”: an office holder’s secret weapon

Published on 13 Mar 2017.

Practitioners are fully aware of the extensive powers available under ss 235 and 236 of the Insolvency Act 1986 (IA 1986) allowing administrators and liquidators as office holders (OHs) to require individuals and organisations to disgorge information.

Perspective - Publication

Make insolvency great again

Published on 08 Feb 2017.

One of the great criticisms of the new President of the United States of America is that his companies filed for bankruptcy four times when he was a business mogul.

Profile

Johnny Cheung

Associate

Perspective - Blog

Stamp duty land tax (SDLT) avoidance and corporate property deals – the importance of timing!

Published on 21 May 2019. By Ben Roberts, Partner

The First-Tier Tribunal has, in a recent decision, caused something of a stir for clients and advisors familiar with the well-trodden (and, usually, tax-efficient) use of offshore unit trusts to hold UK property.

Perspective - Blog

Building on renewable energy #3 – Anaerobic Digestion

Published on 24 Sep 2020.

Anaerobic digestion is the process by which biodegradable materials are broken down in a controlled environment. Whilst being broken down, the materials emit gas (which can be used as a source of renewable energy), and produce heat (which can also be harnessed on or near-to site). The process also leaves a waste material (digestate), which can be used as fertiliser, contributing to the circular economy.

Profile

Jessica Yates

Perspective - Blog

Model Articles deemed unsuitable for sole director companies

Published on 24 May 2022. By Rupert Wyles, Senior Associate

A recent decision of the High Court in Hashmi v Lorimer-Wing [2022] EWHC 191 (Ch) has suggested that the model articles for private companies are not suitable for companies with a sole director appointed.

Perspective - Blog

A licence to kill... a licence

Published on 11 Mar 2019. By Tim Anderson, Partner

In the second of a number of short articles we are producing in relation to businesses in the tech space, we will be discussing a real life example of what not to do when diligencing a tech company and its third party IP licence agreements.

Perspective - Blog

New regulations to permit assignment of receivables under commercial contracts now in force

Published on 11 Jan 2019. By Edward Colville, Partner

After more than four years of consultation, draft regulations and revisions, the Business Contract Terms (Assignment of Receivables) Regulations 2018 (the Regulations) have now taken effect, and apply to all relevant contracts entered into on or after 31 December 2018.

Perspective - Blog

Huawei and UK National Security - A new technology cold war?

Published on 11 Dec 2018. By Neil Brown, Partner and Charles Buckworth, Partner

Chinese technology giant, Huawei, has been making plenty of headlines recently. First, a number of Western governments (including the US, Australia and New Zealand) have banned Huawei equipment from being used in 5G networks, citing national security concerns. Next, Huawei's CFO was arrested in Canada in connection with alleged breaches of international sanctions.

Perspective - Publication

All is not (necessarily) lost: Crypto crime recovery

Published on 30 Jun 2022. By Adam Craggs, Partner

With over 2 million people in the UK now holding and using cryptocurrency, and the Chancellor announcing that a government backed non-fungible token ("NFT") is to be issued by the Royal Mint this summer, the market for crypto-assets is expected to continue to grow in the coming months and years; so much so that legislation is planned to implement a new regulatory regime for the crypto market.

Perspective - Blog

Hong Kong Employment Law Update: Mandatory Provident Fund offsetting mechanism to be abolished after decade-long debate and campaigning

Published on 24 Jun 2022. By Andrea Randall, Partner and Lillian Wong, Associate

Following on from our brief update published on 9 June 2022, this article provides a detailed overview of the amendments put forward by the long-awaited Employment and Retirement Schemes Legislation (Offsetting Arrangement) (Amendment) Bill 2022 (the "Bill"), which was finally passed by the Legislative Council on 9 June 2022. The main feature of the Bill is the abolishment of the offsetting mechanism of the Mandatory Provident Fund ("MPF").

Perspective - Blog

Hong Kong Wage Subsidy Update – Government announces new round of Employment Support Scheme

Published on 27 Apr 2022. By Andrea Randall, Partner and Lillian Wong, Associate

The Government has at last finalized the details of the new round of Employment Support Scheme ("2022 ESS"). The purpose of the 2022 ESS to offer limited time financial support to small and medium-sized enterprises through providing wage subsidies to encourage enterprises to increase employment and to retain employees who would otherwise be made redundant.

Perspective - Blog

Increased penalty for employers who employ overstayers

Published on 29 Nov 2021. By Andrea Randall, Partner

Immigration (Amendment) Ordinance 2021 (“IAO”)

Perspective - Blog

Hong Kong's Legislative Council to consider Cancellation of MPF Offsetting

Published on 06 Oct 2021. By Andrea Randall, Partner

Under the Employment Ordinance, employers can offset long service payment or severance payment due to an employee against the employer's mandatory and voluntary contributions to the Mandatory Provident Fund (MPF), Hong Kong's pension system.

Perspective - Blog

Reimbursement of Maternity Leave Pay Scheme in Hong Kong

Published on 12 Apr 2021. By Andrea Randall, Partner

Hong Kong's statutory maternity leave has been extended from 10 weeks to 14 weeks with effect from 11 December 2020. From 1 April 2021, the Hong Kong Government has started accepting applications to reimburse employers' payment in respect of the extended period of maternity leave.

Perspective - Blog

COVID 19 Your workforce: What on earth is "furlough"?

Published on 24 Mar 2020. By Kelly Thomson, Partner, ESG strategy lead and Patrick Brodie, Partner

Meaning of furlough, especially in the context of companies dealing with the impact of COVID-19.

Perspective - Blog

COVID-19 Your workforce: pay and costs - practical ideas our clients are exploring

Published on 24 Mar 2020. By Patrick Brodie, Partner and Kelly Thomson, Partner, ESG strategy lead

COVID-19 Your workforce: pay and costs - practical ideas our clients are exploring. These are extraordinary times that place extraordinary pressures on all of us, including dealing with your workforce. We set out below some ideas that we are hearing about from our clients and some areas you may wish to think about in terms of your employee costs.

Perspective - Blog

COVID-19 Your workforce: supporting mental health when home working

Published on 24 Mar 2020. By Kelly Thomson, Partner, ESG strategy lead and Patrick Brodie, Partner

COVID-19 Your workforce: supporting mental health when home working. Many of us are working from home during this crisis and while this can be an effective way of working for some, it is less happy for others; loneliness, caring for vulnerable dependants and challenging home environments are all being experienced. There may be members of your teams who fall into these categories.