Search results

Perspective - Blog

North Midland Building Limited v Cyden Homes Limited [2017] EWHC 2414 (TCC): Choose your extension of time provisions carefully

Published on 11 Oct 2017.

North Midland Building Limited v Cyden Homes confirms the primacy of the parties' contract in determining an extension of time. Specifically, in North Midland the High Court held that an amendment made to the construction contract meant that, in a situation of concurrent delay, North Midland Building Ltd (the Contractor) was not entitled to an extension of time from Cyden Homes Ltd (the Employer) and that the prevention principle, had it arisen, would not take precedence over the expressly agreed terms of the contract.

Perspective - Blog

Contractors and Insurers beware - Contractor found to bear the risk of an incorrect standard as fitness for purpose prevails in the Supreme Court

Published on 03 Aug 2017.

This morning the Supreme Court handed down its much anticipated judgment in MT Højgaard A/S v E.ON Climate & Renewables UK Robin Rigg East Limited and another [2017] UKSC 59. The Judgment should be of concern to both contractors and their insurers.

Perspective - Blog

Is it game over for ground rent?

Published on 01 Aug 2017.

Considering the recent Government proposals to change the rules on ground rent and how those proposals may affect developers.

Perspective - Blog

Complex contracts and intricate inconsistencies – a reminder of the court's approach to contractual interpretation

Published on 18 Jul 2017.

In a year in which the Supreme Court will have produced two Judgments on the topic of contractual interpretation, the TCC's judgment in 125 OBS v Lend Lease is a useful reminder of the courts' approach to resolving these disputes and their attempt to find a balance between the so-called literal and commercial approaches to interpretation.

Perspective - Blog

Even More Challenging Times – 5 More Risks Following The Grant of Planning Permission

Published on 14 Jun 2017.

This post is the second in a two-part series in which we highlight ten areas where the risk of a third party challenge against the grant of planning permission might arise. The list we have given is not exhaustive, but all issues fall within the broad parameters for judicial review grounds, being decisions which have been taken irrationality, ultra vires (outside the scope of the authority's powers), or with procedural irregularity.

Perspective - Blog

EIA – a new role for the planning system in considering the health impacts of development?

Published on 10 May 2017.

A summary of the EIA Regulations 2017 and the consideration as part of the planning application process of a proposed development's likely impacts on human health.

Perspective - Blog

Let there be light

Published on 19 Apr 2017.

The importance of light in WELL Building Standards and how it sits within the context of planning law and rights of light

Perspective - Blog

MIPIM: 10 things we learnt about you

Published on 31 Mar 2017.

A round up of things we learnt during our first experience of MIPIM week, from what to wear to how to plan your diary and make the most of your new connections

Perspective - Blog

Engaging with Development – do we always know what we need?

Published on 29 Mar 2017.

Comment on the need for public engagement in the planning and development process, following a ULI presentation on The Well-Tempered City (author Jonathan Rose)

Perspective - Blog

Finally, a victory in the on-going battle against business rates

Published on 03 Mar 2017.

The Supreme Court ruling in Newbigin v Monks represents a welcome and important victory for UK property developers.

Perspective - Blog

Green belt development - don't forget the law!

Published on 13 Feb 2017.

A review of the housing white paper in relation to green belt development noting that the Green Belt (London and Home Counties) Act 1938 is a further hurdle.

Perspective - Blog

Electronic Signatures – the future of executing documents?

Published on 03 Feb 2017.

You could be forgiven for failing to spot the release of The EU Regulation on Electronic Identification and Trust Services in the Internal Market (910/2014/EU) (the Regulation), released post EU referendum. We consider the impact of this and the Law Society's Guidance Note on electronic signatures (the Guidance Note).

Perspective - Blog

Garden Villages - are they necessary?

Published on 09 Jan 2017.

A recent Government announcement has proposed 14 sites across England to be the first garden villages, with 3 further sites to be new garden towns. But with a country full of deserted and derelict buildings, are garden villages and towns the only way forward?

Perspective - Blog

Office to Residential Permitted Development Rights – an update

Published on 08 Aug 2016.

The rights to convert a building from office use to residential without needing to submit a planning application are not new, although a recent decision from the Planning Court have brought them back to the headlines and suggest that they may be more flexible than anticipated.

Perspective - Blog

Freedom of information: access denied by ministerial veto

Published on 04 Feb 2014.

Not since September 2012 when the Attorney General exercised powers under section 53(2) of the Freedom of Information Act 2000 (FOIA) blocking the release of correspondence between Prince Charles and seven government departments has there been a matter likely to attract attention to the use of the ministerial veto.

Perspective - Blog

Court of Appeal's opinion on good faith clauses

Published on 11 Apr 2013.

In our February blog we reported on Compass Group UK and Ireland Ltd (trading as Medirest) v Mid Essex Hospital Services NHS Trust [2012] EWHC 781 (QB) and the implications of the decision on the duty to act in good faith.

Perspective - Blog

Costs overruns in Target Costs contracts

Published on 22 Mar 2013.

Who is liable for costs overruns in a Target Cost contract, and to what extent? AMEC Group recently went to the TCC to appeal against an arbitration decision which found the Secretary of State for Defence ("the Authority") would only be liable for actual costs which were reasonably and properly incurred.

Perspective - Blog

NPPF – 1 year on: smooth transition or wasted opportunity?

Published on 21 Mar 2013.

Given that over 50% of Britain's local councils are still to adopt Local Plans, is the window of opportunity for local residents to take control of development in their local area about to close?

Perspective - Blog

New Kids on the Block : alternative funders in the real estate lending market

Published on 15 Mar 2013.

Over the last couple of years, there has been a surge in real estate lending by non-bank lenders as traditional banks started withdrawing from the market.

Perspective - Blog

Good Faith Clauses

Published on 26 Feb 2013.

There is no general doctrine of good faith in English law and it is not therefore implied into contracts.

Perspective - Blog

JCT Insurance Options: what's the right fit for fit-out?

Published on 18 Feb 2013.

Where a tenant is fitting out premises within a multi-occupied building, the JCT's standard insurance options are not always appropriate and, left unaddressed, place unintended and severe risks on the tenant.

Perspective - Blog

Government property, Kirstie and Phil style?

Published on 01 Feb 2013.

Ok, so Ms Allsopp and Mr Spencer haven’t quite been called in yet, but almost.

Perspective - Blog

Is the Green Deal a great deal?

Published on 29 Jan 2013.

There is no denying the Green Deal has many advantages but consider the deal in relation to short term leases and it may not be as great as it initially seems.

Perspective - Blog

NEC3 Engineering and Construction Contract "Guidance Notes": more important than you realise for interpreting the ECC

Published on 18 Jan 2013.

Certain terms of the NEC3 Engineering and Construction Contract ('ECC') are open to interpretation, and the recent case of E-Nik Ltd v Department for Communities & Local Government [2012] EWHC 3027 (Comm) has cast into doubt whether even something as routine as VAT is crystal-clear under the ECC.

Perspective - Blog

Development incentives – but at what cost?

Published on 14 Jan 2013.

In light of what is starting to appear to be a wholehearted failure to persuade local communities to meet requisite housing targets, Nick Boles last week proposed self-proclaimed "bungs" to local communities.

Perspective - Blog

Leaving customers without signal: the task of re-building the Telecoms Code

Published on 05 Dec 2012.

Now almost 30 years old, the Electronic Communications Code (the 'Code'), falls far short of representing the needs of a swiftly developing communications network.

Perspective - Blog

H&M: Brave New World?

Published on 27 Nov 2012.

We have all been involved in lease negotiations where there are differences of opinion as to what is or is not institutionally acceptable.

Perspective - Blog

End of the line for Village Greens?

Published on 14 Nov 2012.

Nothing can be more frustrating for a developer to see its scheme delayed or worse still derailed by an application for the registration of land as a town or village green ("TVG").

Profile

Saskia Mautner

Associate

Perspective - Publication

RICS disciplinary process: an overview for surveyors

Published on 27 Aug 2024. By Ben Goodier, Partner and Emma Wherry, Senior Associate and Sarah O'Callaghan, Senior Associate and Laura Sponti, Associate

Download our complete guide to the procedure involved in a disciplinary investigation against a chartered surveyor.

Perspective - Blog

Construction disciplinary trends analysis #3: fraud and dishonesty

Published on 12 Aug 2024. By Ben Goodier, Partner and Emma Wherry, Senior Associate and Aimee Talbot, Knowledge Lawyer

This article is the third instalment in our mini-series analysing trends in disciplinary decisions involving construction professionals, with insight from our specialist disciplinary team.

Perspective - Blog

Construction disciplinary trends analysis #2: engagement letters – worth more than the paper they're written on!

Published on 21 Feb 2024. By Ben Goodier, Partner and Emma Wherry, Senior Associate and Aimee Talbot, Knowledge Lawyer

This article is the second in our mini-series analysing trends in disciplinary decisions involving construction professionals, with insight from our specialist disciplinary team.

Perspective - Blog

Construction disciplinary trends analysis #1: continuing professional development

Published on 16 Oct 2023. By Ben Goodier, Partner and Emma Wherry, Senior Associate and Aimee Talbot, Knowledge Lawyer

This article is the first in our mini-series analysing trends in disciplinary decisions involving construction professionals, with insight from our specialist disciplinary team.

Perspective - Publication

Staying green and true: navigating the new FCA anti-greenwashing rule

Published on 30 Aug 2024. By Mike Newham, Partner and Sophie Tuson, Senior Associate and Catherine Zakarias-Welch, Knowledge Lawyer

In an era where sustainability is now firmly on the investor agenda and under increasing scrutiny, the FCA has recently introduced a new 'anti-greenwashing' rule to prevent firms from exaggerating the green or social credentials of their products and services. The implications of the new rule are significant, with the risk of regulatory action and civil claims for non-compliance. Against this backdrop, IR professionals can play a key role in helping ensure transparency with investors, raising the firm's profile in the sustainability space and mitigating legal risk.

Perspective - Publication

Green claims update: July 2024

Published on 31 Jul 2024. By Oliver Bray, Senior Partner and Ciara Cullen, Partner and Hettie Homewood , Senior Associate and Sophie Tuson, Senior Associate

Welcome to our round-up of the key legal and regulatory developments relating to green claims.

Perspective - Blog

The EU's Green Claims Directive

Published on 24 Jul 2024. By Oliver Bray, Senior Partner and Ciara Cullen, Partner and Hettie Homewood , Senior Associate and Sophie Tuson, Senior Associate

The EU's proposed Green Claims Directive (GCD) sets out expansive new rules for companies making green claims in the EU.

Perspective - Publication

Green claims update: June 2024

Published on 02 Jul 2024. By Oliver Bray, Senior Partner and Ciara Cullen, Partner and Hettie Homewood , Senior Associate and Sophie Tuson, Senior Associate

Welcome to our round-up of the key legal and regulatory developments relating to green claims.

Perspective - Blog

Environmental sustainability: a snapshot of a changing regulatory landscape

Published on 01 Jul 2024. By Sophie Tuson, Senior Associate

Sophie Tuson charts the key legal developments in the UK and EU across the product lifecycle and flags practical considerations for businesses.

Perspective - Snapshot