Search results

North Midland Building Limited v Cyden Homes Limited [2017] EWHC 2414 (TCC): Choose your extension of time provisions carefully

Published on 11 Oct 2017.

North Midland Building Limited v Cyden Homes confirms the primacy of the parties' contract in determining an extension of time. Specifically, in North Midland the High Court held that an amendment made to the construction contract meant that, in a situation of concurrent delay, North Midland Building Ltd (the Contractor) was not entitled to an extension of time from Cyden Homes Ltd (the Employer) and that the prevention principle, had it arisen, would not take precedence over the expressly agreed terms of the contract.

Contractors and Insurers beware - Contractor found to bear the risk of an incorrect standard as fitness for purpose prevails in the Supreme Court

Published on 03 Aug 2017.

This morning the Supreme Court handed down its much anticipated judgment in MT Højgaard A/S v E.ON Climate & Renewables UK Robin Rigg East Limited and another [2017] UKSC 59. The Judgment should be of concern to both contractors and their insurers.

Is it game over for ground rent?

Published on 01 Aug 2017.

Considering the recent Government proposals to change the rules on ground rent and how those proposals may affect developers.

Complex contracts and intricate inconsistencies – a reminder of the court's approach to contractual interpretation

Published on 18 Jul 2017.

In a year in which the Supreme Court will have produced two Judgments on the topic of contractual interpretation, the TCC's judgment in 125 OBS v Lend Lease is a useful reminder of the courts' approach to resolving these disputes and their attempt to find a balance between the so-called literal and commercial approaches to interpretation.

Even More Challenging Times – 5 More Risks Following The Grant of Planning Permission

Published on 14 Jun 2017.

This post is the second in a two-part series in which we highlight ten areas where the risk of a third party challenge against the grant of planning permission might arise. The list we have given is not exhaustive, but all issues fall within the broad parameters for judicial review grounds, being decisions which have been taken irrationality, ultra vires (outside the scope of the authority's powers), or with procedural irregularity.

EIA – a new role for the planning system in considering the health impacts of development?

Published on 10 May 2017.

A summary of the EIA Regulations 2017 and the consideration as part of the planning application process of a proposed development's likely impacts on human health.

Let there be light

Published on 19 Apr 2017.

The importance of light in WELL Building Standards and how it sits within the context of planning law and rights of light

MIPIM: 10 things we learnt about you

Published on 31 Mar 2017.

A round up of things we learnt during our first experience of MIPIM week, from what to wear to how to plan your diary and make the most of your new connections

Engaging with Development – do we always know what we need?

Published on 29 Mar 2017.

Comment on the need for public engagement in the planning and development process, following a ULI presentation on The Well-Tempered City (author Jonathan Rose)

Finally, a victory in the on-going battle against business rates

Published on 03 Mar 2017.

The Supreme Court ruling in Newbigin v Monks represents a welcome and important victory for UK property developers.

Green belt development - don't forget the law!

Published on 13 Feb 2017.

A review of the housing white paper in relation to green belt development noting that the Green Belt (London and Home Counties) Act 1938 is a further hurdle.

Electronic Signatures – the future of executing documents?

Published on 03 Feb 2017.

You could be forgiven for failing to spot the release of The EU Regulation on Electronic Identification and Trust Services in the Internal Market (910/2014/EU) (the Regulation), released post EU referendum. We consider the impact of this and the Law Society's Guidance Note on electronic signatures (the Guidance Note).

Garden Villages - are they necessary?

Published on 09 Jan 2017.

A recent Government announcement has proposed 14 sites across England to be the first garden villages, with 3 further sites to be new garden towns. But with a country full of deserted and derelict buildings, are garden villages and towns the only way forward?

Office to Residential Permitted Development Rights – an update

Published on 08 Aug 2016.

The rights to convert a building from office use to residential without needing to submit a planning application are not new, although a recent decision from the Planning Court have brought them back to the headlines and suggest that they may be more flexible than anticipated.

Freedom of information: access denied by ministerial veto

Published on 04 Feb 2014.

Not since September 2012 when the Attorney General exercised powers under section 53(2) of the Freedom of Information Act 2000 (FOIA) blocking the release of correspondence between Prince Charles and seven government departments has there been a matter likely to attract attention to the use of the ministerial veto.

Court of Appeal's opinion on good faith clauses

Published on 11 Apr 2013.

In our February blog we reported on Compass Group UK and Ireland Ltd (trading as Medirest) v Mid Essex Hospital Services NHS Trust [2012] EWHC 781 (QB) and the implications of the decision on the duty to act in good faith.

Costs overruns in Target Costs contracts

Published on 22 Mar 2013.

Who is liable for costs overruns in a Target Cost contract, and to what extent? AMEC Group recently went to the TCC to appeal against an arbitration decision which found the Secretary of State for Defence ("the Authority") would only be liable for actual costs which were reasonably and properly incurred.

NPPF – 1 year on: smooth transition or wasted opportunity?

Published on 21 Mar 2013.

Given that over 50% of Britain's local councils are still to adopt Local Plans, is the window of opportunity for local residents to take control of development in their local area about to close?

New Kids on the Block : alternative funders in the real estate lending market

Published on 15 Mar 2013.

Over the last couple of years, there has been a surge in real estate lending by non-bank lenders as traditional banks started withdrawing from the market.

Good Faith Clauses

Published on 26 Feb 2013.

There is no general doctrine of good faith in English law and it is not therefore implied into contracts.

JCT Insurance Options: what's the right fit for fit-out?

Published on 18 Feb 2013.

Where a tenant is fitting out premises within a multi-occupied building, the JCT's standard insurance options are not always appropriate and, left unaddressed, place unintended and severe risks on the tenant.

Government property, Kirstie and Phil style?

Published on 01 Feb 2013.

Ok, so Ms Allsopp and Mr Spencer haven’t quite been called in yet, but almost.

Is the Green Deal a great deal?

Published on 29 Jan 2013.

There is no denying the Green Deal has many advantages but consider the deal in relation to short term leases and it may not be as great as it initially seems.

NEC3 Engineering and Construction Contract "Guidance Notes": more important than you realise for interpreting the ECC

Published on 18 Jan 2013.

Certain terms of the NEC3 Engineering and Construction Contract ('ECC') are open to interpretation, and the recent case of E-Nik Ltd v Department for Communities & Local Government [2012] EWHC 3027 (Comm) has cast into doubt whether even something as routine as VAT is crystal-clear under the ECC.

Development incentives – but at what cost?

Published on 14 Jan 2013.

In light of what is starting to appear to be a wholehearted failure to persuade local communities to meet requisite housing targets, Nick Boles last week proposed self-proclaimed "bungs" to local communities.

Leaving customers without signal: the task of re-building the Telecoms Code

Published on 05 Dec 2012.

Now almost 30 years old, the Electronic Communications Code (the 'Code'), falls far short of representing the needs of a swiftly developing communications network.

H&M: Brave New World?

Published on 27 Nov 2012.

We have all been involved in lease negotiations where there are differences of opinion as to what is or is not institutionally acceptable.

End of the line for Village Greens?

Published on 14 Nov 2012.

Nothing can be more frustrating for a developer to see its scheme delayed or worse still derailed by an application for the registration of land as a town or village green ("TVG").

Accessory liability: when will directors be held liable for IP infringements committed by their companies – and what is counted as "profits"?

Published on 20 Jun 2024. By Emma Dunnill, Senior Associate and Rory Graham, Associate

The Supreme Court in Lifestyle Equities CV & Anor v Ahmed & Anor [2024] UKSC 17, has allowed an appeal by two company directors who were found liable as accessories to trade mark infringement by the company in which they were directors. The decision provides helpful clarification on the required elements for accessory liability in the context of IP right infringement claims and confirms the sums to be included in an account of profits if liability is established (spoiler alert: a director's salary is not considered to be "profit").

Online platforms should Swatch out: Samsung found liable for infringing third-party content available on the Samsung Galaxy App store

Published on 22 Jan 2024. By Sarah Mountain, Partner and Emma Dunnill, Senior Associate and Zoe Harvey, Associate

The Court of Appeal in Montres Breguet SA v Samsung Electronics [2023] EWCA Civ 1478 has dismissed Samsung's appeal and upheld a first instance decision which found it liable for trade mark infringement in relation to third-party watch faces available on the Samsung Galaxy App store. This judgment provides guidance on what constitutes "use" of a sign by an online app store and the applicability of the e-Commerce Directive hosting defence.

The Sky's the limit for trade mark applications. Or is it?

Published on 12 Jul 2023. By Sarah Mountain, Partner and Ellie Chakarto, Associate and Noonie Holmes, Associate

Against a Backdrop of Rising Corporate Insolvencies HMRC Joint and Several Liability Notices: Should Directors be Concerned?

Published on 11 Apr 2023. By Paul Bagon, Partner and Laura Capece Galeota, Associate

It is widely anticipated that the next twelve months could be a challenging period for many businesses in the UK and that there could be a significant rise in the number of companies in financial distress.

BTI 2014 LLC v Sequana SA and others – Supreme Court decision

Published on 06 Oct 2022. By Tim Moynihan, Partner

The Judgment of the Supreme Court in BTI 2014 LLC v Sequana SA was handed down on 5 October 2022.

Carluccio's serves up a rescue recipe

Published on 28 Apr 2020. By Paul Bagon, Partner and Olivia Whitehead, Hospitality & Events Executive

On Friday 24 April, RPC hosted a 30 minute webinar on the interaction of furloughing and insolvency law.

COVID-19: the supply chain

Published on 20 Apr 2020. By Paul Bagon, Partner and Tim Moynihan, Partner

Concerns regarding the strength of UK supply chains and the consequences which arise when links in the chain fail, are not new and were recently subject to significant scrutiny in the context of Brexit negotiations. But with COVID-19 causing a host of new problems for already stressed supply chains, what can businesses do to protect themselves?

COVID-19: Good news on wrongful trading provisions but why should directors tread carefully?

Published on 09 Apr 2020. By Tim Moynihan, Partner

The Government has launched a number of initiatives to assist companies and businesses to trade through the current financial stress. But what should directors still be aware of as they steer their organisations through these unprecedented times?

COVID-19: The suspension of wrongful trading provisions and a moratorium for businesses in restructuring – what is the likely impact on your business?

Published on 31 Mar 2020. By Paul Bagon, Partner and James Whelan, Senior Associate

COVID-19: On 28 March 2020 the Business Secretary announced further new far-reaching measures to help businesses combat the financial impact of COVID-19. What it the likely impact of the suspension of wrongful trading provisions and a moratorium for businesses in restructuring on your business?

UK Government wants understanding of video games to move to the next level

Published on 12 Jun 2023. By Gowri Chandrashekar, Senior Associate and Zoe Harvey, Associate

On 30 May 2023, the UK Government published a Video Games Research Framework which encourages research on video games and emerging game-related technologies.

CMA ends its investigation into online console gaming subscription practices

Published on 14 Jun 2022. By Jonathan Greenway, Senior Associate and Joshua Charalambous, Partner

The UK Competition Markets Authority (CMA) has now closed its investigation into subscription practices in the online console gaming sector after key players Sony, Nintendo and Microsoft committed to making improvements to their contract terms with a view to better protecting customers.

How should Financial Institutions manage the rise of non-financial misconduct?

Published on 19 Feb 2024. By James Wickes, Partner and Amber Oldershaw, Associate

Over the last few months, Parliament's Treasury Committee has sought to examine the many barriers faced by women in financial services through the aptly named "Sexism in the City" inquiry.

Quid game – fixed costs; pick your battles

Published on 30 Jan 2024. By Thom Lumley, Partner and Chris Gower, Associate and Sally Lord, Knowledge Lawyer

Ordinarily, the claims that make the headlines are those that have the highest value or the most significant impact on the public. With the costs landscape ever-changing in civil claims, without careful planning and strategy, even modest claims can end up biting defendants in the longer-term.

Castle caper condoned? Court of Appeal rules on dishonest condonation and aggregation under solicitors policy in Discovery Land v AXIS

Published on 17 Jan 2024. By Graham Reid, Partner and Will Sefton, Partner and Head of Professional and Financial Risks and Aimee Talbot, Knowledge Lawyer

On 15 January 2024 the Court of Appeal handed down judgment in Discovery Land Company LLC and others v Axis Specialty Europe SE [2024] EWCA Civ 7. The case concerns the ability of a solicitors’ insurer to decline cover for a claim on grounds of dishonesty and, in particular, the meaning of “condonation” of dishonesty. It also concerns how the aggregation clause operates in a solicitors’ professional indemnity insurance policy.

The Terminator: A Tale of Two Insurance Claims

Published on 19 Dec 2023. By Peter Mansfield, Partner

It is 2029, and the Machines are losing their war with Humanity. What to do?

Project Angel Bidco v AXIS - what are the key takeaways for warranty and indemnity insurers?

Published on 30 Nov 2023. By James Wickes, Partner and Matthew Wood, Senior Associate and Matt Ward, Trainee Solicitor

On 31 October 2023, the London Circuit Commercial Court gave judgment in Project Angel Bidco Limited (in administration) v Axis Managing Agency Limited & Ors (2023) EWHC 2649.

Wordings do matter

Published on 06 Nov 2023. By Tamsin Hyland, Partner

Contract drafting has been brass tacks for lawyers since the dawn of time. In its broadest terms, it involves putting the scope of a bargain reached between parties into clear and effective language.

Storm Babet, flooding and the insurance implications

Published on 24 Oct 2023. By Victoria Sherratt, Partner and Andrew Roper, Partner and Aimee Talbot, Knowledge Lawyer

Subtropical cyclone Storm Babet is currently responsible for over 350 flood warnings in the UK, with more flood warnings expected later this week.

Getting to know Global Access Lawyers

Published on 09 Oct 2023. By Carmel Green, Partner and Simon Laird, Global Head of Insurance

Global Access Lawyers brings together some of the worlds leading insurance law practices. In the following pages get to know the different law firms that make up Global Access, who we are, where we operate and the kind of work we do. We hope you find this useful to understand the international reach of Global Access.

Court of Appeal finds in favour of FSCS on scope of the Policyholder Protection Rules (PRR)

Published on 14 Sep 2023. By Tamsin Hyland, Partner

Tamsin Hyland explores the recent judgment of JR (On the application of Manchikalapati v FSCS [2023] EWCA Civ 1006) and its relevance to insurance policy wording.

What does the FRC's proposed corporate governance overhaul mean for D&O exposures?

Published on 04 Jul 2023. By James Wickes, Partner and Aimee Talbot, Knowledge Lawyer

The Financial Reporting Council (FRC) has now published the draft new UK Corporate Governance Code following the Government's requirements that it incorporate more robust internal control and prudent and effective risk management requirements. The deadline for responses to the FRC's consultation is 13 September 2023.

Consumer duty and claims handling – beware of sludge practices

Published on 10 May 2023. By Jonathan Charwat, Partner

The Consumer Duty is a new regulatory framework developed by the Financial Conduct Authority (FCA) aimed at creating a higher standard of consumer protection in the retail markets. The FCA expects the Consumer Duty to be a significant shift for the market in terms of its expectations on firms and in this blog we consider this shift in the context of insurance claims handling.