Search results

Perspective - Blog

North Midland Building Limited v Cyden Homes Limited [2017] EWHC 2414 (TCC): Choose your extension of time provisions carefully

Published on 11 Oct 2017.

North Midland Building Limited v Cyden Homes confirms the primacy of the parties' contract in determining an extension of time. Specifically, in North Midland the High Court held that an amendment made to the construction contract meant that, in a situation of concurrent delay, North Midland Building Ltd (the Contractor) was not entitled to an extension of time from Cyden Homes Ltd (the Employer) and that the prevention principle, had it arisen, would not take precedence over the expressly agreed terms of the contract.

Perspective - Blog

Contractors and Insurers beware - Contractor found to bear the risk of an incorrect standard as fitness for purpose prevails in the Supreme Court

Published on 03 Aug 2017.

This morning the Supreme Court handed down its much anticipated judgment in MT Højgaard A/S v E.ON Climate & Renewables UK Robin Rigg East Limited and another [2017] UKSC 59. The Judgment should be of concern to both contractors and their insurers.

Perspective - Blog

Is it game over for ground rent?

Published on 01 Aug 2017.

Considering the recent Government proposals to change the rules on ground rent and how those proposals may affect developers.

Perspective - Blog

Complex contracts and intricate inconsistencies – a reminder of the court's approach to contractual interpretation

Published on 18 Jul 2017.

In a year in which the Supreme Court will have produced two Judgments on the topic of contractual interpretation, the TCC's judgment in 125 OBS v Lend Lease is a useful reminder of the courts' approach to resolving these disputes and their attempt to find a balance between the so-called literal and commercial approaches to interpretation.

Perspective - Blog

Even More Challenging Times – 5 More Risks Following The Grant of Planning Permission

Published on 14 Jun 2017.

This post is the second in a two-part series in which we highlight ten areas where the risk of a third party challenge against the grant of planning permission might arise. The list we have given is not exhaustive, but all issues fall within the broad parameters for judicial review grounds, being decisions which have been taken irrationality, ultra vires (outside the scope of the authority's powers), or with procedural irregularity.

Perspective - Blog

EIA – a new role for the planning system in considering the health impacts of development?

Published on 10 May 2017.

A summary of the EIA Regulations 2017 and the consideration as part of the planning application process of a proposed development's likely impacts on human health.

Perspective - Blog

Let there be light

Published on 19 Apr 2017.

The importance of light in WELL Building Standards and how it sits within the context of planning law and rights of light

Perspective - Blog

MIPIM: 10 things we learnt about you

Published on 31 Mar 2017.

A round up of things we learnt during our first experience of MIPIM week, from what to wear to how to plan your diary and make the most of your new connections

Perspective - Blog

Engaging with Development – do we always know what we need?

Published on 29 Mar 2017.

Comment on the need for public engagement in the planning and development process, following a ULI presentation on The Well-Tempered City (author Jonathan Rose)

Perspective - Blog

Finally, a victory in the on-going battle against business rates

Published on 03 Mar 2017.

The Supreme Court ruling in Newbigin v Monks represents a welcome and important victory for UK property developers.

Perspective - Blog

Green belt development - don't forget the law!

Published on 13 Feb 2017.

A review of the housing white paper in relation to green belt development noting that the Green Belt (London and Home Counties) Act 1938 is a further hurdle.

Perspective - Blog

Electronic Signatures – the future of executing documents?

Published on 03 Feb 2017.

You could be forgiven for failing to spot the release of The EU Regulation on Electronic Identification and Trust Services in the Internal Market (910/2014/EU) (the Regulation), released post EU referendum. We consider the impact of this and the Law Society's Guidance Note on electronic signatures (the Guidance Note).

Perspective - Blog

Garden Villages - are they necessary?

Published on 09 Jan 2017.

A recent Government announcement has proposed 14 sites across England to be the first garden villages, with 3 further sites to be new garden towns. But with a country full of deserted and derelict buildings, are garden villages and towns the only way forward?

Perspective - Blog

Office to Residential Permitted Development Rights – an update

Published on 08 Aug 2016.

The rights to convert a building from office use to residential without needing to submit a planning application are not new, although a recent decision from the Planning Court have brought them back to the headlines and suggest that they may be more flexible than anticipated.

Perspective - Blog

Freedom of information: access denied by ministerial veto

Published on 04 Feb 2014.

Not since September 2012 when the Attorney General exercised powers under section 53(2) of the Freedom of Information Act 2000 (FOIA) blocking the release of correspondence between Prince Charles and seven government departments has there been a matter likely to attract attention to the use of the ministerial veto.

Perspective - Blog

Court of Appeal's opinion on good faith clauses

Published on 11 Apr 2013.

In our February blog we reported on Compass Group UK and Ireland Ltd (trading as Medirest) v Mid Essex Hospital Services NHS Trust [2012] EWHC 781 (QB) and the implications of the decision on the duty to act in good faith.

Perspective - Blog

Costs overruns in Target Costs contracts

Published on 22 Mar 2013.

Who is liable for costs overruns in a Target Cost contract, and to what extent? AMEC Group recently went to the TCC to appeal against an arbitration decision which found the Secretary of State for Defence ("the Authority") would only be liable for actual costs which were reasonably and properly incurred.

Perspective - Blog

NPPF – 1 year on: smooth transition or wasted opportunity?

Published on 21 Mar 2013.

Given that over 50% of Britain's local councils are still to adopt Local Plans, is the window of opportunity for local residents to take control of development in their local area about to close?

Perspective - Blog

New Kids on the Block : alternative funders in the real estate lending market

Published on 15 Mar 2013.

Over the last couple of years, there has been a surge in real estate lending by non-bank lenders as traditional banks started withdrawing from the market.

Perspective - Blog

Good Faith Clauses

Published on 26 Feb 2013.

There is no general doctrine of good faith in English law and it is not therefore implied into contracts.

Perspective - Blog

JCT Insurance Options: what's the right fit for fit-out?

Published on 18 Feb 2013.

Where a tenant is fitting out premises within a multi-occupied building, the JCT's standard insurance options are not always appropriate and, left unaddressed, place unintended and severe risks on the tenant.

Perspective - Blog

Government property, Kirstie and Phil style?

Published on 01 Feb 2013.

Ok, so Ms Allsopp and Mr Spencer haven’t quite been called in yet, but almost.

Perspective - Blog

Is the Green Deal a great deal?

Published on 29 Jan 2013.

There is no denying the Green Deal has many advantages but consider the deal in relation to short term leases and it may not be as great as it initially seems.

Perspective - Blog

NEC3 Engineering and Construction Contract "Guidance Notes": more important than you realise for interpreting the ECC

Published on 18 Jan 2013.

Certain terms of the NEC3 Engineering and Construction Contract ('ECC') are open to interpretation, and the recent case of E-Nik Ltd v Department for Communities & Local Government [2012] EWHC 3027 (Comm) has cast into doubt whether even something as routine as VAT is crystal-clear under the ECC.

Perspective - Blog

Development incentives – but at what cost?

Published on 14 Jan 2013.

In light of what is starting to appear to be a wholehearted failure to persuade local communities to meet requisite housing targets, Nick Boles last week proposed self-proclaimed "bungs" to local communities.

Perspective - Blog

Leaving customers without signal: the task of re-building the Telecoms Code

Published on 05 Dec 2012.

Now almost 30 years old, the Electronic Communications Code (the 'Code'), falls far short of representing the needs of a swiftly developing communications network.

Perspective - Blog

H&M: Brave New World?

Published on 27 Nov 2012.

We have all been involved in lease negotiations where there are differences of opinion as to what is or is not institutionally acceptable.

Perspective - Blog

End of the line for Village Greens?

Published on 14 Nov 2012.

Nothing can be more frustrating for a developer to see its scheme delayed or worse still derailed by an application for the registration of land as a town or village green ("TVG").

Profile

Saskia Mautner

Associate

Perspective - Podcast

The World Bank

Published on 27 Oct 2021.

In this episode, Jamieson Smith, Chief Suspension and Debarment Officer at the World Bank, joins Alice Kemp and Alex Haines, Barrister at Outer Temple Chambers, to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to work in every major area of development.

Perspective - Podcast

The Global Fund

Published on 27 Oct 2021.

In this episode, Patricia Diaz Dennis, the Sanctions Panel Chair, and Philippe Dewilde, Senior Legal Counsel at the Global Fund, join Robert Waterson and Alice Kemp to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to defeat HIV, TB and malaria and ensure a healthier, safer, more equitable future for all.

Perspective - Podcast

The Inter-American Development Bank

Published on 27 Oct 2021.

In this episode, Juan Ronderos, the Sanctions Officer, and Samir Fahoum, the Principal Integrity Officer, at the Inter-American Development Bank join Alice Kemp and Alex Haines, Barrister at Outer Temple Chambers, to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to improve lives in Latin America and the Caribbean.

Perspective - Podcast

The European Bank for Reconstruction & Development

Published on 27 Oct 2021.

In this episode, Paul Kearney, Chief Counsel and Enforcement Commissioner, and Rohan Schaap, the Director of Investigations, at the European Bank for Reconstruction & Development, join Alice Kemp and Alex Haines, Barrister at Outer Temple Chambers, to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to foster the transition towards open market-oriented economies and to promote private and entrepreneurial initiative.

Perspective - Podcast

The New Development Bank

Published on 27 Oct 2021.

In this episode, Dr Srinivas Yanamandra, Chief of Compliance at the New Development Bank, joins Alice Kemp and John McKendrick QC, of Outer Temple Chamber, to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to support infrastructure and sustainable development efforts in BRICS and other underserved, emerging economies for faster development through innovation and cutting-edge technology.

Perspective - Podcast

The Caribbean Development Bank

Published on 27 Oct 2021.

In this episode, Dr Toussant Boyce, Head of the Office of Integrity, Compliance and Accountability at the Caribbean Development Bank, joins Robert Waterson and Alice Kemp to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to reduce poverty and transform lives through sustainable, resilient and inclusive development.

Perspective - Podcast

The Asian Infrastructure Investment Bank

Published on 27 Oct 2021.

In this episode, Jean-Marc Lafreniere, Head of the Integrity Function, and Hamid Sharif, Managing Director, at the Asian Infrastructure Investment Bank, join Robert Waterson and Alice Kemp to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to build green infrastructure with sustainability, innovation and connectivity at its core.

Perspective - Podcast

The European Investment Bank

Published on 27 Oct 2021.

In this episode, Dominik Adamski, Head of the Fraud Detection Unit, and Mirela Lascu, a member of the Inspectorate General, at the European Investment Bank join Robert Waterson and Alice Kemp to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to back the European Green Deal and make Europe carbon-neutral.

Perspective - Podcast

The Nordic Investment Bank

Published on 27 Oct 2021.

In this episode, Mark Butler, Chief Compliance Officer at the Nordic Investment Bank, joins Alice Kemp and Alex Haines, Barrister at Outer Temple Chambers, to discuss how this giant of international finance is fighting against the cancer of corruption in its mission to finance projects that improve productivity and benefit the environment of the Nordic and Baltic countries.

Perspective - Blog

Look to the future: Trainees take on 2019

Published on 25 Jan 2019.

The trainees didn't fare too badly with their 2018 predictions. They doubted England's ability to make it past the group stages of the World Cup, but foresaw how Brexit would dominate the news agenda. They over-optimistically predicted the introduction of automated bundling, but came very close on the value of Bitcoin. Read on to see this year's predictions.

Perspective - Blog

Brexit - a legal analysis: IP rights

Published on 28 Jun 2016.

IP rights in the UK are all influenced and moulded to a greater or lesser degree by European law.

Perspective - Publication

“Gagging orders”: an office holder’s secret weapon

Published on 13 Mar 2017.

Practitioners are fully aware of the extensive powers available under ss 235 and 236 of the Insolvency Act 1986 (IA 1986) allowing administrators and liquidators as office holders (OHs) to require individuals and organisations to disgorge information.

Perspective - Publication

Make insolvency great again

Published on 08 Feb 2017.

One of the great criticisms of the new President of the United States of America is that his companies filed for bankruptcy four times when he was a business mogul.

Profile

Johnny Cheung

Associate

Perspective - Publication

Ransoms and Sanctions and Fines (oh my!)

Published on 04 Sep 2023. By Richard Breavington, Partner and Helen Monachan, Associate

Ransomware attacks are happening all the time. Just the other month, the Cl0p ransomware gang claimed responsibility for the exploitation of a zero-day vulnerability in the MOVEit Transfer tool.

Perspective - Publication

Ransoms and Sanctions and Fines (oh my!)

Published on 04 Sep 2023. By Richard Breavington, Partner and Helen Monachan, Associate

Ransomware attacks are happening all the time. Just the other month, the Cl0p ransomware gang claimed responsibility for the exploitation of a zero-day vulnerability in the MOVEit Transfer tool.

Perspective - Publication

Law passed to regulate Significant Investments in Singapore Entities

Published on 12 Jan 2024. By Kenneth Leong, Partner and Jemima Holly Ang, Associate

The Significant Investments Review Bill (the "Bill") was recently passed by Parliament on 9 January 2024, and is expected to take effect in the first half of the year.

Perspective - Blog

Consumer duty and claims handling – beware of sludge practices

Published on 10 May 2023. By Jonathan Charwat, Partner

The Consumer Duty is a new regulatory framework developed by the Financial Conduct Authority (FCA) aimed at creating a higher standard of consumer protection in the retail markets. The FCA expects the Consumer Duty to be a significant shift for the market in terms of its expectations on firms and in this blog we consider this shift in the context of insurance claims handling.

Profile

Sarah Chiang

Associate

Perspective - Blog

EU AI ACT-ion stations

Published on 29 Sep 2023. By Helen Armstrong, Partner and Charles Buckworth, Partner

The EU is forging ahead with its vision for AI. With wrapping up talks on the EU AI Act between the EU governments, the Commission and the parliamentary negotiators imminent, we bring you up to date on the EU's risk based approach, the scope of the Act, a timeline, key points that will form the basis of the discussions and next steps.

Perspective - Blog

What To Know About AI Fraudsters Before Facing Disputes

Published on 29 Aug 2023. By Dan Wyatt, Partner and Christopher Whitehouse, Senior Associate

Fraudsters are quick to weaponise new technological developments and artificial intelligence is proving no exception, with AI-assisted scams increasingly being reported in the news, including most recently one using a likeness of a BBC broadcaster.